North Carolina General Statutes 143-134.3. No damage for delay clause
Current as of: 2024 | Check for updates
|
Other versions
Terms Used In North Carolina General Statutes 143-134.3
- Contract: A legal written agreement that becomes binding when signed.
- Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
- state: when applied to the different parts of the United States, shall be construed to extend to and include the District of Columbia and the several territories, so called; and the words "United States" shall be construed to include the said district and territories and all dependencies. See North Carolina General Statutes 12-3
No contractual language forbidding or limiting compensable damages for delays caused solely by the owner or its agent may be enforced in any construction contract let by any board or governing body of the State, or of any institution of State government, or of any county, city, town, or other political subdivision thereof. For purposes of this section, the phrase “owner or its agent” does not include prime contractors or their subcontractors. (1997-489, s. 1.)