Connecticut General Statutes 31-52 – Preference to state citizens in construction of public buildings. Enforcement of violations
(a) In the employment of mechanics, laborers and workmen in the construction, remodeling or repairing of any public building, by the state or any of its agents or by persons contracting therewith, preference shall be given to citizens of the state, and, if they cannot be obtained in sufficient numbers, then to citizens of the United States. Any contractor who knowingly and wilfully employs any person in violation of any provision of this subsection shall be fined two hundred dollars for each week or fraction of a week each such person is so employed.
Terms Used In Connecticut General Statutes 31-52
- Contract: A legal written agreement that becomes binding when signed.
- Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
- Evidence: Information presented in testimony or in documents that is used to persuade the fact finder (judge or jury) to decide the case for one side or the other.
(b) Each contract for the construction or repair of any building under the supervision of the state or any of its agents shall contain the following provisions: “In the employment of labor to perform the work specified herein, preference shall be given to citizens of the United States, who are, and continuously for at least three months prior to the date hereof have been, residents of the labor market area, as established by the Labor Commissioner, in which such work is to be done, and if no such qualified person is available, then to citizens who have continuously resided in the county in which the work is to be performed for at least three months prior to the date hereof, and then to citizens of the state who have continuously resided in the state at least three months prior to the date hereof.” In no event shall said provisions be deemed to abrogate or supersede, in any manner, any provision regarding residence requirements contained in a collective bargaining agreement to which the contractor is a party.
(c) No person who receives an award or contract for public works projects from the state, or who receives an order or contract for which a portion of funds is derived from the state, shall knowingly employ nonresidents of the state while residents who may qualify for such work are reasonably available for employment. In the employment of nonresidents, the construction supervisor or construction inspector assigned to the public works project shall verify that the contracting employer, by reasonable efforts, sought to obtain construction job applicants from existing employment sources in Connecticut.
(d) The agent contracting on behalf of the state or any political subdivision thereof shall investigate promptly any alleged violation of this section or section 31-52a. If said agent finds evidence of such a violation, he shall immediately notify the alleged violator of such evidence and allegations. If the alleged violator fails to take corrective action within one week, or to produce evidence which satisfies said agent that no violation has occurred, said agent shall (1) institute a civil action to recover as liquidated damages for the violation of the contract an amount equal to the wages paid to any employees employed in violation of this section or section 31-52a and cost of suit, including reasonable attorney’s fees and (2) notify the office of the state’s attorney in the judicial district for the area in which such work was performed so that appropriate criminal action may be instituted against the alleged violator.
(e) In contracts so financed preference in employment shall be given to citizens of the United States or any possession thereof.
(f) Nothing in this section shall abrogate or supersede any provision regarding residence requirements in a collective bargaining agreement to which the contractor is a party.