Kansas Statutes 16-1907. Provisions waiving right to collect damages for delays, void, unenforceable
Current as of: 2023 | Check for updates
|
Other versions
Terms Used In Kansas Statutes 16-1907
- Contract: A legal written agreement that becomes binding when signed.
- Contract: means a contract or agreement concerning construction made and entered into by and between an owner and a contractor, a contractor and a subcontractor or a subcontractor and another subcontractor. See Kansas Statutes 16-1902
- Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
Any provision in a contract that purports to waive the rights of a party to the contract to collect damages for delays caused by another party to the contract shall be void, unenforceable and against public policy. This provision is not intended to create a contract between parties where a contract did not otherwise exist.