Kentucky Statutes 26A.168 – Reports on status of court facilities projects and contingency fund
Current as of: 2024 | Check for updates
|
Other versions
(1) The Administrative Office of the Courts shall provide to the Capital Projects and Bond Oversight Committee, at the committee’s January, April, July, and October regular meetings, a status report of all incomplete court facilities projects. The Capital Projects and Bond Oversight Committee shall prescribe data elements for the quarterly status reports. For each project, the status report shall include:
(a) The project title;
(b) The county in which the project is located;
(c) The scope and use allowance authorized for the project in the judicial branch budget, and any increases to the scope or use allowance under KRS § 26A.164;
(d) The current status of the project;
(e) Estimated completion date of the project;
(f) An explanation of any delay or major change in the project, including deletion or modification of project components; and
(g) Any other information that the committee requests.
(2) On August 1 of each year, the Administrative Office of the Courts shall prepare a financial report on the court facility use allowance contingency fund for the fiscal year ending on June 30 of that year. The report shall include, with explanations, allotments, expenditures, encumbrances, and the available balance.
Effective: June 8, 2011
History: Amended 2011 Ky. Acts ch. 73, sec. 4, effective June 8, 2011. — Amended
2002 Ky. Acts ch. 328, sec. 2, effective July 15, 2002. — Created 2000 Ky. Acts ch.
496, sec. 6, effective July 14, 2000.
(a) The project title;
Terms Used In Kentucky Statutes 26A.168
- branch budget: means an enactment by the General Assembly which provides appropriations and establishes fiscal policies and conditions for the biennial financial plan for the judicial branch, the legislative branch, and the executive branch, which shall include a separate budget bill for the Transportation Cabinet. See Kentucky Statutes 446.010
- Fiscal year: The fiscal year is the accounting period for the government. For the federal government, this begins on October 1 and ends on September 30. The fiscal year is designated by the calendar year in which it ends; for example, fiscal year 2006 begins on October 1, 2005 and ends on September 30, 2006.
- Oversight: Committee review of the activities of a Federal agency or program.
- Year: means calendar year. See Kentucky Statutes 446.010
(b) The county in which the project is located;
(c) The scope and use allowance authorized for the project in the judicial branch budget, and any increases to the scope or use allowance under KRS § 26A.164;
(d) The current status of the project;
(e) Estimated completion date of the project;
(f) An explanation of any delay or major change in the project, including deletion or modification of project components; and
(g) Any other information that the committee requests.
(2) On August 1 of each year, the Administrative Office of the Courts shall prepare a financial report on the court facility use allowance contingency fund for the fiscal year ending on June 30 of that year. The report shall include, with explanations, allotments, expenditures, encumbrances, and the available balance.
Effective: June 8, 2011
History: Amended 2011 Ky. Acts ch. 73, sec. 4, effective June 8, 2011. — Amended
2002 Ky. Acts ch. 328, sec. 2, effective July 15, 2002. — Created 2000 Ky. Acts ch.
496, sec. 6, effective July 14, 2000.