Massachusetts General Laws ch. 260 sec. 2B – Tort actions arising from improvements to real property
Section 2B. Action of tort for damages arising out of any deficiency or neglect in the design, planning, construction or general administration of an improvement to real property, other than that of a public agency as defined in section thirty-nine A of chapter seven shall be commenced only within three years next after the cause of action accrues; provided, however, that in no event shall such actions be commenced more than six years after the earlier of the dates of: (1) the opening of the improvement to use; or (2) substantial completion of the improvement and the taking of possession for occupancy by the owner.
Terms Used In Massachusetts General Laws ch. 260 sec. 2B
- Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
- Real property: Land, and all immovable fixtures erected on, growing on, or affixed to the land.
- Tort: A civil wrong or breach of a duty to another person, as outlined by law. A very common tort is negligent operation of a motor vehicle that results in property damage and personal injury in an automobile accident.
Actions of tort for damages arising out of any deficiency or neglect in the design, planning, construction, or general administration of an improvement to real property of a public agency, as defined in said section thirty-nine A shall be commenced only within three years next after the cause of action accrues; provided, however, that in no event shall actions be commenced more than six years after the earlier of the dates of: (1) official acceptance of the project by the public agency; (2) the opening of the real property to public use; (3) the acceptance by the contractor of a final estimate prepared by the public agency pursuant to chapter thirty, section thirty-nine G; or (4) substantial completion of the work and the taking possession for occupancy by the awarding authority.