Oregon Statutes 279C.380 – Performance bond; payment bond; waiver of bonds
(1) Except as provided in ORS § 279C.390, a successful bidder for a public improvement contract shall promptly execute and deliver to the contracting agency the following bonds:
Terms Used In Oregon Statutes 279C.380
- Amendment: A proposal to alter the text of a pending bill or other measure by striking out some of it, by inserting new language, or both. Before an amendment becomes part of the measure, thelegislature must agree to it.
- Contract: A legal written agreement that becomes binding when signed.
- Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
- Obligation: An order placed, contract awarded, service received, or similar transaction during a given period that will require payments during the same or a future period.
- Person: includes individuals, corporations, associations, firms, partnerships, limited liability companies and joint stock companies. See Oregon Statutes 174.100
(a) A performance bond in an amount equal to the full contract price conditioned on the faithful performance of the contract in accordance with the plans, specifications and conditions of the contract. The performance bond must be solely for the protection of the contracting agency that awarded the contract and any public agency or agencies for whose benefit the contract was awarded. If the public improvement contract is with a single person to provide both design and construction of a public improvement, the obligation of the performance bond for the faithful performance of the contract required by this paragraph must also be for the preparation and completion of the design and related services covered under the contract. Notwithstanding when a cause of action, claim or demand accrues or arises, the surety is not liable after final completion of the contract, or longer if provided for in the contract, for damages of any nature, economic or otherwise and including corrective work, attributable to the design aspect of a design-build project, or for the costs of design revisions needed to implement corrective work. A contracting agency may waive the requirement of a performance bond. A contracting agency may permit the successful bidder to submit a cashier’s check or certified check in lieu of all or a portion of the required performance bond.
(b) A payment bond in an amount equal to the full contract price, solely for the protection of claimants under ORS § 279C.600.
(2) If the public improvement contract is with a single person to provide construction manager/general contractor services, in which a guaranteed maximum price may be established by an amendment authorizing construction period services following preconstruction period services, the contractor shall provide the bonds required by subsection (1) of this section upon execution of an amendment establishing the guaranteed maximum price. The contracting agency shall also require the contractor to provide bonds equal to the value of construction services authorized by any early work amendment in advance of the guaranteed maximum price amendment. Such bonds must be provided before construction starts.
(3) Each performance bond and each payment bond must be executed solely by a surety company or companies holding a certificate of authority to transact surety business in this state. The bonds may not constitute the surety obligation of an individual or individuals. The performance and payment bonds must be payable to the contracting agency or to the public agency or agencies for whose benefit the contract was awarded, as specified in the solicitation documents, and shall be in a form approved by the contracting agency.
(4) In cases of emergency, or when the interest or property of the contracting agency or the public agency or agencies for whose benefit the contract was awarded probably would suffer material injury by delay or other cause, the requirement of furnishing a good and sufficient performance bond and a good and sufficient payment bond for the faithful performance of any public improvement contract may be excused, if a declaration of such emergency is made in accordance with rules adopted under ORS § 279A.065.
(5) This section applies only to public improvement contracts with a value, estimated by the contracting agency, of more than $100,000 or, in the case of contracts for highways, bridges and other transportation projects, more than $50,000. [2003 c.794 § 118; 2005 c.103 § 20; 2013 c.522 § 9]