Oregon Statutes 279C.540 – Maximum hours of labor on public contracts; holidays; exceptions; liability to workers; rules
(1) When labor is employed by the state or a county, school district, municipality, municipal corporation or subdivision thereof through a contractor, a person may not be required or permitted to labor more than 10 hours in any one day, or 40 hours in any one week, except in cases of necessity or emergency or when the public policy absolutely requires it, in which event, the person so employed for excessive hours shall receive at least time and a half pay:
Terms Used In Oregon Statutes 279C.540
- Contract: A legal written agreement that becomes binding when signed.
- Corporation: A legal entity owned by the holders of shares of stock that have been issued, and that can own, receive, and transfer property, and carry on business in its own name.
- Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
- Person: includes individuals, corporations, associations, firms, partnerships, limited liability companies and joint stock companies. See Oregon Statutes 174.100
(a)(A) For all overtime in excess of eight hours in any one day or 40 hours in any one week when the work week is five consecutive days, Monday through Friday; or
(B) For all overtime in excess of 10 hours in any one day or 40 hours in any one week when the work week is four consecutive days, Monday through Friday; and
(b) For all work performed on Saturday and on the following legal holidays:
(A) Each Sunday.
(B) New Year’s Day on January 1.
(C) Memorial Day on the last Monday in May.
(D) Independence Day on July 4.
(E) Labor Day on the first Monday in September.
(F) Thanksgiving Day on the fourth Thursday in November.
(G) Christmas Day on December 25.
(2) An employer shall give notice in writing to employees who perform work under subsection (1) of this section, either at the time of hire or before commencement of work on the contract, or by posting a notice in a location frequented by employees, of the number of hours per day and days per week that employees may be required to work.
(3) For the purpose of this section, each time a legal holiday, other than Sunday, listed in subsection (1) of this section falls on Sunday, the succeeding Monday shall be recognized as a legal holiday. Each time a legal holiday listed in subsection (1) of this section falls on Saturday, the preceding Friday shall be recognized as a legal holiday.
(4) Subsections (1) to (3) of this section do not apply to a public improvement contract or a contract for services if the contractor is a party to a collective bargaining agreement in effect with any labor organization.
(5) When specifically agreed to under a written labor-management negotiated labor agreement, an employee may be paid at least time and a half pay for work performed on any legal holiday specified in ORS § 187.010 and 187.020 that is not listed in subsection (1) of this section.
(6) This section does not apply to contracts for personal services as defined in ORS § 279C.100, provided that persons employed under such contracts shall receive at least time and a half pay for work performed on the legal holidays specified in subsection (1)(b)(B) to (G) of this section and for all overtime worked in excess of 40 hours in any one week, except for individuals under personal services contracts who are excluded under ORS § 653.010 to 653.261 or under 29 U.S.C. § 201 to 209 from receiving overtime.
(7) Subsections (1) and (2) of this section do not apply to contracts for services at a county fair or for other events authorized by a county fair board if persons employed under the contract receive at least time and a half for work in excess of 10 hours in any one day or 40 hours in any one week.
(8)(a) Subsections (1) and (2) of this section do not apply to contracts for services. However, persons employed under such contracts shall receive at least time and a half pay for work performed on the legal holidays specified in a collective bargaining agreement or in subsection (1)(b)(B) to (G) of this section and for all time worked in excess of 10 hours in any one day or in excess of 40 hours in any one week, whichever is greater.
(b) An employer shall give notice in writing to employees who work on a contract for services, either at the time of hire or before commencement of work on the contract, or by posting a notice in a location frequented by employees, of the number of hours per day and days per week that the employees may be required to work.
(9) Any contractor or subcontractor or contractor’s or subcontractor’s surety that violates the provisions of this section is liable to the affected employees in the amount of their unpaid overtime wages and in an additional amount equal to the unpaid overtime wages as liquidated damages. If the violation results from willful falsification of payroll records, the contractor or subcontractor or contractor’s or subcontractor’s surety is liable to the affected employees in the amount of their unpaid overtime wages and an additional amount equal to twice the unpaid overtime wages as liquidated damages.
(10) An action to enforce liability to employees under subsection (9) of this section may be brought as an action on the contractor’s payment bond as provided for in ORS § 279C.610.
(11) In accordance with ORS Chapter 183, the Commissioner of the Bureau of Labor and Industries may adopt rules to carry out the provisions of this section. [2003 c.794 § 144; 2005 c.103 § 31]