Texas Civil Practice and Remedies Code 16.008 – Architects, Engineers, Interior Designers, and Landscape Architects Furnishing Design, Planning, or Inspection of Construction of Improvements
(a) Except as provided by Subsection (a-1), a person must bring suit for damages for a claim listed in Subsection (b) against a registered or licensed architect, engineer, interior designer, or landscape architect in this state, who designs, plans, or inspects the construction of an improvement to real property or equipment attached to real property, not later than 10 years after the substantial completion of the improvement or the beginning of operation of the equipment in an action arising out of a defective or unsafe condition of the real property, the improvement, or the equipment.
(a-1) A governmental entity must bring suit for damages for a claim listed in Subsection (b) against a registered or licensed architect, engineer, interior designer, or landscape architect in this state, who designs, plans, or inspects the construction of an improvement to real property or equipment attached to real property, not later than eight years after the substantial completion of the improvement or the beginning of operation of the equipment in an action arising out of a defective or unsafe condition of the real property, the improvement, or the equipment. This subsection does not apply to a claim arising out of:
(1) a contract entered into by the Texas Department of Transportation;
(2) a project that receives money from the state highway fund or a federal fund designated for highway and mass transit spending; or
(3) a civil works project, as that term is defined under § 2269.351, Government Code.
Terms Used In Texas Civil Practice and Remedies Code 16.008
- Contract: A legal written agreement that becomes binding when signed.
- Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
- Person: includes corporation, organization, government or governmental subdivision or agency, business trust, estate, trust, partnership, association, and any other legal entity. See Texas Government Code 311.005
- Personal property: All property that is not real property.
- Property: means real and personal property. See Texas Government Code 311.005
- Real property: Land, and all immovable fixtures erected on, growing on, or affixed to the land.
- Written: includes any representation of words, letters, symbols, or figures. See Texas Government Code 311.005
- Year: means 12 consecutive months. See Texas Government Code 311.005
(b) This section applies to suit for:
(1) injury, damage, or loss to real or personal property;
(2) personal injury;
(3) wrongful death;
(4) contribution; or
(5) indemnity.
(c) If the claimant presents a written claim for damages, contribution, or indemnity to the architect, engineer, interior designer, or landscape architect within the applicable limitations period, the period is extended for:
(1) two years from the date the claim is presented, for a claim to which Subsection (a) applies; or
(2) one year from the date the claim is presented, for a claim to which Subsection (a-1) applies.