Louisiana Revised Statutes 39:1661 – Contract clauses; administration
Terms Used In Louisiana Revised Statutes 39:1661
- Agency: as used in this Chapter shall have the same meaning ascribed to it as provided in Louisiana Revised Statutes 39:1556
- Chief procurement officer: means the person holding the position created in Louisiana Revised Statutes 39:1556
- Contract: A legal written agreement that becomes binding when signed.
- Contract: means all types of state agreements, regardless of what they may be called, including orders and documents purporting to represent grants, which are for the purchase or disposal of supplies, services, major repairs, or any other item. See Louisiana Revised Statutes 39:1556
- Contractor: means any person having a contract with a governmental body. See Louisiana Revised Statutes 39:1556
- Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
- Equitable: Pertaining to civil suits in "equity" rather than in "law." In English legal history, the courts of "law" could order the payment of damages and could afford no other remedy. See damages. A separate court of "equity" could order someone to do something or to cease to do something. See, e.g., injunction. In American jurisprudence, the federal courts have both legal and equitable power, but the distinction is still an important one. For example, a trial by jury is normally available in "law" cases but not in "equity" cases. Source: U.S. Courts
- in writing: means the product of any method of forming characters on paper, other materials, or viewable screen, which can be read, retrieved, and reproduced, including information that is electronically transmitted and stored. See Louisiana Revised Statutes 39:1556
- Procurement: means the buying, purchasing, renting, leasing, or otherwise obtaining any supplies, services, or major repairs. See Louisiana Revised Statutes 39:1556
- Supplies: means all property, including but not limited to equipment, materials, insurance, and leases on immovable property excluding land or a permanent interest in land. See Louisiana Revised Statutes 39:1556
A. Contract clauses. Regulations may permit or require the inclusion of clauses providing for equitable adjustments in prices, time for performance, or other contract provisions, as appropriate, including but not limited to the following subjects:
(1) The unilateral right of the state to order in writing changes in the work within the general scope of the contract in any one or more of the following:
(a) Drawings, designs, or specifications, if the supplies to be furnished are to be specially manufactured for the state in accordance therewith.
(b) Method of shipment or packing.
(c) Place of delivery.
(d) Security for contract performance.
(e) Insurance requirements including as appropriate but not limited to general liability, automobile coverage, workers’ compensation, and errors and omissions.
(f) Beginning and ending dates of the contract.
(g) Maximum compensation to be paid the contractor.
(2) The unilateral right of the state to order in writing temporary stopping of the work or delaying of performance.
(3) Variations between estimated quantities of work in a contract and actual quantities.
(4) Manufacturers’ design drawings shall be supplied in duplicate for all state buildings, to the appropriate state agency at the conclusion of contract.
B. Additional contract clauses. Regulations may permit or require the inclusion in state contracts of clauses providing for appropriate remedies and including but not limited to the following subjects:
(1) Liquidated damages as appropriate.
(2) Specified excuses for delay or nonperformance.
(3) Termination of the contract for default, and
(4) Termination of the contract in whole or in part for the convenience of the state.
C. In the event any contractor fails to fulfill or comply with the terms of any contract, the chief procurement officer may award the contract to the next lowest responsible bidder subject to acceptance by that bidder and charge the difference in cost to the defaulting vendor.
Added by Acts 1979, No. 715, §1, eff. July 1, 1980. Amended by Acts 1982, No. 710, §1; Acts 2011, No. 210, §2, eff. July 1, 2011; Acts 2014, No. 864, §2, eff. Jan. 1, 2015.