Nevada Revised Statutes 338.1377 – Local government public works: Adoption of criteria for qualification of bidders
Except as otherwise provided in NRS 338.1382, if a governing body that sponsors or finances a public work elects to award contracts for public works pursuant to the provisions of NRS 338.1377 to 338.139, inclusive, the governing body shall adopt the following criteria for determining whether a person who has applied pursuant to NRS 338.1379 is qualified to bid on contracts for public works of the local government:
Terms Used In Nevada Revised Statutes 338.1377
- Authorized representative: means a person designated by a public body to be responsible for the development, solicitation, award or administration of contracts for public works pursuant to this chapter. See Nevada Revised Statutes 338.010
- Bankruptcy: Refers to statutes and judicial proceedings involving persons or businesses that cannot pay their debts and seek the assistance of the court in getting a fresh start. Under the protection of the bankruptcy court, debtors may discharge their debts, perhaps by paying a portion of each debt. Bankruptcy judges preside over these proceedings.
- Contract: A legal written agreement that becomes binding when signed.
- Contract: means a written contract entered into between a contractor and a public body for the provision of labor, materials, equipment or supplies for a public work. See Nevada Revised Statutes 338.010
- Contractor: means :
(a) A person who is licensed pursuant to the provisions of chapter 624 of NRS. See Nevada Revised Statutes 338.010
- Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
- Evidence: Information presented in testimony or in documents that is used to persuade the fact finder (judge or jury) to decide the case for one side or the other.
- Governing body: means the board, council, commission or other body in which the general legislative and fiscal powers of a local government are vested. See Nevada Revised Statutes 338.010
- Local government: means every political subdivision or other entity which has the right to levy or receive money from ad valorem or other taxes or any mandatory assessments, and includes, without limitation, counties, cities, towns, boards, school districts and other districts organized pursuant to chapters 244A, 318, 318A, 379, 474, 538, 541, 543 and 555 of NRS, Nevada Revised Statutes 338.010
- person: means a natural person, any form of business or social organization and any other nongovernmental legal entity including, but not limited to, a corporation, partnership, association, trust or unincorporated organization. See Nevada Revised Statutes 0.039
- Public work: means any project for the new construction, repair or reconstruction of a project financed in whole or in part from public money for:
(a) Public buildings;
(b) Jails and prisons;
(c) Public roads;
(d) Public highways;
(e) Public streets and alleys;
(f) Public utilities;
(g) Publicly owned water mains and sewers;
(h) Public parks and playgrounds;
(i) Public convention facilities which are financed at least in part with public money; and
(j) All other publicly owned works and property. See Nevada Revised Statutes 338.010
- Subcontractor: means a person who:
(a) Is licensed pursuant to the provisions of chapter 624 of NRS or performs such work that the person is not required to be licensed pursuant to chapter 624 of NRS; and
(b) Contracts with a contractor, another subcontractor or a supplier to provide labor, materials or services for a construction project. See Nevada Revised Statutes 338.010
- Supplier: means a person who provides materials, equipment or supplies for a construction project. See Nevada Revised Statutes 338.010
1. Whether the applicant possesses a valid contractor‘s license of a class corresponding to the work to be required by the local government;
2. Whether the applicant has the ability to obtain the necessary bonding for the work to be required by the local government;
3. Whether the applicant has successfully completed an appropriate number of projects as determined by the local government, but not to exceed five projects, during the 5 years immediately preceding the date of application of similar size, scope or type as the work to be required by the local government;
4. Whether the principal personnel employed by the applicant have the necessary professional qualifications and experience for the work to be required by the local government;
5. Whether the applicant has breached any contracts with a public agency or person in this State or any other state during the 5 years immediately preceding the date of application;
6. Whether the applicant has been disqualified from being awarded a contract pursuant to NRS 338.017 or 338.13895;
7. Whether the applicant has been convicted of a violation for discrimination in employment during the 2 years immediately preceding the date of application;
8. Whether the applicant has the ability to obtain and maintain insurance coverage for public liability and property damage within limits sufficient to protect the applicant and all the subcontractors of the applicant from claims for personal injury, accidental death and damage to property that may arise in connection with the work to be required by the local government;
9. Whether the applicant has established a safety program that complies with the requirements of chapter 618 of NRS;
10. Whether the applicant has been disciplined or fined by the State Contractors’ Board or another state or federal agency for conduct that relates to the ability of the applicant to perform the work to be required by the local government;
11. Whether, during the 5 years immediately preceding the date of application, the applicant has filed as a debtor under the provisions of the United States Bankruptcy Code;
12. Whether the application of the applicant is truthful and complete; and
13. Whether, during the 5 years immediately preceding the date of application, the applicant has, as a result of causes within the control of the applicant or a subcontractor or supplier of the applicant, failed to perform any contract:
(a) In the manner specified by the contract and any change orders initiated or approved by the person or governmental entity that awarded the contract or its authorized representative;
(b) Within the time specified by the contract unless extended by the person or governmental entity that awarded the contract or its authorized representative; or
(c) For the amount of money specified in the contract or as modified by any change orders initiated or approved by the person or governmental entity that awarded the contract or its authorized representative. Evidence of the failures described in this subsection may include, without limitation, the assessment of liquidated damages against the applicant, the forfeiture of any bonds posted by the applicant, an arbitration award granted against the applicant or a decision by a court of law against the applicant.