For contracts for projects that involve the demolition of property for a right-of-way, the director of transportation shall include in the contract adequate provision for liquidated damages and a requirement that the contractor inform the department of the method for disposal of demolition debris prior to the start of work.

lawyer at desk

Ask a legal question, get an answer ASAP!
Click here to chat with a lawyer about your rights.

Terms Used In Ohio Code 5525.22

  • Contract: A legal written agreement that becomes binding when signed.
  • Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
  • Property: means real and personal property. See Ohio Code 1.59

Last updated April 21, 2022 at 3:42 PM

  Previous section
Next section  
 Chapter 5525 Contents